当前位置：好文网>实用文>合同范本>英文合同

英文合同

【精华】英文合同三篇

　　随着时间的推移，我们用到合同的地方越来越多，签订合同是减少和防止发生争议的重要措施。那么合同要怎么拟定？想必这让大家都很苦恼吧，下面是小编帮大家整理的英文合同3篇，仅供参考，希望能够帮助到大家。

【精华】英文合同三篇

英文合同篇1

　　Address:

　　Telephone：

　　Party B: Address:

　　Telephone：

　　According to the provisions of the contract law of the People's Republic of China and the relevant laws and regulations, Party B accepts the entrustment of the first party and entrustment with the two parties through consultation.

　　First, entrustment:

　　Two, the way of payment:

　　1, Party A shall pay 40% of the total cost of the contract, namely ____ yuan (RMB) to Party B, Party B received the money after the start of design.

　　2. Party B shall provide complete design draft. After confirmation by Party A, the total amount of the total cost shall be paid.

　　Three. Design time:

　　1, Party B shall provide complete design draft in __ working days.

　　2, Party B shall complete the design work of party a company commissioned in _____ years __ month __ day (delay time by party a reason, work time should be postponed).

　　Four. The responsibilities and obligations of the two parties:

　　1, Party B shall, according to the requirements of Party A to finish the related work on time.

　　2, Party A has the responsibility to fully cooperate with Party B to carry out the work stipulated in this contract and provide relevant information according to the needs of Party B. Party A is responsible for the consequences caused by Party A's delay in the required information.

　　3. Party A shall provide complete design information before the start of the design, due to Party A's provision of incomplete information and changes in content.

　　For structural changes, Party A shall pay the corresponding cost of design changes.

　　4. After Party B receives the complete design information of Party A, it is designed to facilitate the determination of the style of Party A, and Party B begins to design the first draft after the style is determined.

　　5, Party A has the right to put forward amendments to the works designed by Party B. The first draft Party A can make a structural modification. After the first draft is determined, the structural modifications should be made. Party A shall pay the corresponding cost separately.

　　6. The consequences of the delay due to the amendment of Party A shall be borne by Party A.

　　7, due to the loss caused by post production by Party A alone, the loss caused by problems in the design of the product is borne by Party B. The legal liability caused by copyright, for the economic disputes shall be borne by Party a..

　　8. During the course of the project, Party B is attached to the brand of Party A and shall not sign any form of cooperation agreement with the customer in the identity of Party B.

　　Five. The agreement on intellectual property rights:

　　1, Party B has the copyright of the works completed by the design. After the settlement of all the fees designed by Party A, Party B may transfer the copyright of the works to Party A.

　　2. Before Party A has not paid all the cost of the design, the copyright of the works designed by Party B shall be attributed to Party B, and Party A does not have any right to the work.

　　3. Party A shall have the right to investigate the legal liability of Party A if it uses or amends the works designed by Party B before the payment is not paid.

　　Six. Liability for breach of contract:

　　1, Party A terminates the contract before the completion of the first draft of the design work. The prepaid expenses have no right to request the return. If a party terminates the contract after the completion of the first draft of Party B's work, it shall pay the full design fee.

　　2. If Party B terminates the contract without proper reasons, the fees charged shall be returned to Party A.

　　Seven, if a party or a party has a dispute over the performance of this contract, it shall be settled amicable through negotiation. If either party fails to negotiate, any Party A and B can submit it to the Beijing Arbitration Commission for arbitration.

　　Eight, the contract is effective from the date of signature by Gai Zhang and both parties. The contract is two copies in one form. Each party has one contract signed by the other party (Gai Zhang), which has the same legal effect.

　　Nine. If there is no matter in this contract, the two parties shall jointly discuss and supplement the contract. The contents of the supplement and modification are equally valid to this contract.

　　Party A: Party B:

　　(signature seal) (signature seal)

　　Date: Date:

　　中文版

　　地址：

　　电话：

　　乙方：地址：

　　电话：

　　依据《中华人民共和国合同法》和有关法规的规定，乙方接受甲方的委托，就委托设计事项，双方经协商一致，签订本合同，信守执行：

　　一、委托事项：

　　二、付款方式：

　　1、甲方需在合同签订之时支付总费用的40% ，即____元(人民币)给乙方，乙方收到甲方的款项后开始设计。

　　2、乙方提供完整的设计稿，甲方确认后,应当即付清总费用的全部余款。

　　三、设计时间：

　　1、乙方需在__个工作日内提供比较完整的设计稿。

　　2、乙方需在_____年__月__日完成甲方公司委托的设计工作 (由甲方原因耽误的时间，完稿时间应顺延)。

　　四、双方的责任与义务：

　　1、乙方应按甲方要求按质按量按时完成相关设计工作。

　　2、甲方有责任全力配合乙方开展本合同所规定的工作，并根据乙方需要提供相关资料。由于甲方提供所需资料延误时间造成的后果，由甲方承担。

　　3、甲方应在设计开始前提供完整的设计资料，由于甲方提供资料不完整、内容改动而造成的设

　　计结构改动，甲方须另行支付相应的设计改动费用。

　　4、乙方收到甲方的完整设计资料后进行部分小样设计以方便甲方确定风格，风格确定后乙方开始进行初稿设计。

　　5、甲方有权对乙方所设计的作品提出修改意见，初稿甲方可提出一次结构上的修改，初稿确定后的'结构修改，甲方须另行支付相应费用。

　　6、因甲方修改，延误时间造成的后果，由甲方承担。

　　7、由于后期制作造成的损失由甲方独自承担，由于制作物设计出现问题造成的损失由乙方承担。因版权、文责所引发的法律责任，经济纠纷由甲方承担。

　　8、设计项目期间乙方挂靠于甲方品牌之中，不得以乙方身份单独与客户签订任何形式的合作协议。

　　五、知识产权约定：

　　1、乙方对设计完成的作品享有著作权。甲方将委托设计的所有费用结算完毕后，乙方可将作品著作权转让给甲方。

　　2、甲方在未付清所有委托设计费用之前，乙方设计的作品著作权归乙方，甲方对该作品不享有任何权利。

　　3、甲方在余款未付清之前擅自使用或者修改使用乙方设计的作品而导致的侵权，乙方有权追究其法律责任。

　　六、违约责任：

　　1、甲方在设计作品初稿完成前终止合同，其预付的费用无权要求退回；甲方在乙方作品初稿完成后终止合同的，应当支付全额的设计费用。

　　2、乙方如无正当理由提前终止合同，所收取的费用应当全部退回给甲方。

　　七、甲乙双方如因履行本合同发生纠纷，应当友好协商解决，协商不成的，甲乙双方任何一方均可向北京仲裁委员会提请仲裁解决。

　　八、本合同自甲乙双方签字盖章之日起生效，本合同一式两份，双方各持对方签字（盖章）合同一份，具有同等的法律效力。

　　九、本合同如有未尽事宜，由甲乙双方共同讨论补充或修改。补充和修改的内容与本合同具有同等效力。

　　甲方：乙方：

　　（签字盖章）（签字盖章）

　　日期：日期：

英文合同篇2

　　CONTRACT

　　КОНТРАКТ

　　No.( Нет.)

　　Company Name:

　　And (и)

　　Company Name:

　　signed this Contract as following:

　　подписали настоящий Договор о следующем:

　　1. THE SUBJECT OF THE CONTRACT

　　Предмет контракта

　　1.1. The SELLER sells and the BUYER buys the following

　　Покупатель согласился купить, продавец согласен продать следующие продукты:

　　Место погрузки: КНР, г. Shenzhen

　　1.2 In case of discrepancies between the Chinese text, English text and Russia text of this contract , the English text shall prevail.

　　В случае расхождения, оригинальным признается вариант контракта на английском языке.

　　2. QUANTITY AND QUALITY

　　КОЛИЧЕСТВО И КАЧЕСТВО:

　　2.1. Quantity of the GOODS should supplied according to the Contract

　　Количество товара должно поставляться в соответствии с Договором

　　2.2. The BUYER and the SELLER bear the full responsibility for monitoring procedure of quality at mutual trust to each other.

　　The BUYER can send representative to SELLER’s warehouse to inspect the finished product.

　　The SELLER must control the product quality continuously. And the SELLER must keep paper record for some control process.

　　ПОКУПАТЕЛЬ и ПРОДАВЕЦ несут полную ответственность за проведение контроля качества при взаимном доверии друг к другу.

　　Покупатель может послать представителя для склада ПРОДАВЦА для проверки готовой продукции. Продавец обязан контролировать качество продукции непрерывно. И продавец должен держать бумаги запись в течение некоторого процесса управления.

　　2.3 Warranty time: within 18 months after buyer receipt of the goods

　　Время гарантированности: Все оборудование имеет заводскую гарантию 18 месяцев с момента получения оборудования покупателем.

　　3. BASIC TERMS OF DELIVERY OF GOODS

　　ОСНОВНЫЕ УСЛОВИЯ ПОСТАВКИ ТОВАРОВ

　　3.1 SELLER delivers the GOODS to the BUYER on terms of CIF , seaport Odessa, Ukraine, (According to the International terms Regulations, revision 20xx).

　　Продавец предоставляет товар в распоряжение покупателя на условиях CIF, морского порта Одесса, Украина, (В соответствии с Международными терминов Положения, пересмотр 20xx г.).

　　3.2 The delivery time is six months after received the down payment

　　Срок поставки через шесть месяцев после получил авансовый платеж

　　4. PRICE OF GOODS AND TOTAL AMOUNT OF THE CONTRACT

　　ЦЕНА ТОВАРОВ И ОБЩАЯ СУММА КОНТРАКТА

　　4.1 The price is fixed

　　цена фиксирована

　　4.1 The price for the GOODS is fixed in USD

　　Цена на товар фиксируется в долларах США

　　4.2 The total price of the contract is USD ,

　　Общая сумма контракта составляет: USD_____

　　4.3 Packing charges , international sea shipping and insurance costs are included.

　　Упаковка обвинения, международные морские перевозки и страхования затраты включаются.

　　5.TERMS OF PAYMENT AND DELIVERY

　　УСЛОВИЯ ОПЛАТЫ И ДОСТАВКА

　　5. 1 Down payment: 35% of total contract price paid by T/T. After receiving payment, the Seller starts producing equipment

　　Первый взнос: 35% от общей стоимости контракта оплачивается T / T. После получения предоплаты, Продавец начинает изготавливать оборудование

　　5.2 payment before delivery: 60% of total contract price paid by T/T. A After receiving payment, the Seller

　　shall deliver the equipments soon,

　　оплата до поставки: 60% от общей стоимости контракта оплачивается T / T. После получения

　　оплаты, Продавец поставляет оборудование в ближайшее время,

　　5.3Quality guarantee deposit: 5% of total contract price paid by T/T. After receipt of the equipment and check its packaging by the buyer within 7 days

　　качество гарантийный депозит: 5% от общей стоимости контракта оплачивается T / T. После

　　получении оборудования и проверки его комплектации Покупатель в течении 7 дней

　　6. PACKING AND MARKING

　　УПАКОВКА И МАРКИРОВКА

　　7. FORCE MAJEURE

　　ФОРС-МАЖОР

　　If the force majeure event occurs (War, civil strife, earthquakes, fires, floods, etc.)

　　The two sides could not foresee its occurrence, when the consequences of its impact on the contract, Disputing party needs to send the certificate documents to other party to prove the force majeure event occurs. The documents should send to other party within 10 days.This documents can avoid the responsibility.

　　Если происходит событие форс-мажор (Война, гражданские беспорядки, землетрясения, пожары, наводнения и т.д.)

　　Обе стороны не могли предвидеть его появление, когда последствия ее воздействия на договоре, оспаривая партию необходимо отправить сертификат документов другой стороне, чтобы доказать

　　происходит событие форс-мажорные обстоятельства. Документы должны отправить на другой стороной в течение 10 дней. Этот документ может избежать ответственности.

　　8. ARBITRATION

　　Арбитраж

　　All disputes arising from the execution of , or in connection with this contract, shall be settled amicably through friendly negotiation. In case no settlement can be reached through negotiation, the case shall then be submitted to The China International Economic and Trade Arbitration Commission, Beijing, China,for arbitration in accordance with its Rules of Arbitration.

　　9. OTHER CONDITIONS

　　другие условия

　　In all other respects, if any matter is agreed by both parties, the contract can make modify.

　　This contract is signed in two copies in English and Russian. Each party get one copy, each copy is legal Во всех других отношениях, если любой вопрос согласовывается обеими сторонами, договор может делать изменения.

　　10. BANK DETAILS

　　БАНКОВСКИЕ РЕКВИЗИТЫ

　　10.1 BUYER(Продавец):

　　10.2 SELLER(Продавец):

　　BANK INFORMATION(Реквизиты банка )

　　COMPANY NAME: Fuchun Ind Dev Co.,Ltd. Shenzhen

　　ADDRESS: 15E XINHAI BUILDING,NANSHAN AVENUE, NANSHAN DISTRICT, SHENZHEN 518052,CHINA

　　TEL: 86-755-26575526 FAX: 86-755-26575026

　　Bank A/C NO: 745859587561

　　Bank Name: SONG RI DING SHENG SUB-BRANCH, SHENZHEN BRANCH, BANK OF CHINA Address of Bank: Songridingsheng Building North, No 9996,Shennan Road,Yuehai Sub-District, Nanshan District, Shenzhen ,China

　　SWIFT CODE: BKCHCNBJ45A

　　11.SIGNATURE OF EACH PARTY

　　ПОДПИСЬ каждая сторона

英文合同篇3

　　购货合同

　　PURCHASE CONTRACT

　　合同编号:

　　Contract No.:

　　签订日期:

　　Date：

　　签订地点:

　　Signed at:

　　买方：

　　The Buyers:

　　地址：

　　Address:

　　联系人：

　　Contact:

　　电话(Tel):

　　传真(Fax):

　　邮箱/E-mail：

　　卖方：

　　The Sellers:

　　地址：

　　Address:

　　联系人：

　　Contact:

　　电话(Tel):

　　传真(Fax):

　　邮箱/E-mail：

　　经买卖双方确认根据下列条款订立本合同：

　　The undersigned Sellers and Buyers have confirmed this contract in accordance with the terms and conditions stipulated below:

　　1. 商品名称及规格

　　Name of Commodity & Specification

　　2. 数量

　　Quantity

　　3. 单价

　　Unit Price

　　4. 总金额

　　Amount

　　5. 包装

　　Packing

　　6. 交货时间

　　Delivery Time

　　7. 交货地点

　　Delivery Place

　　8. 运输方式

　　Means of Transport

　　9. 保险

　　Insurance

　　由_______方按发票金额的______%投保__________，加保______从______到______。

　　To be covered by for % of the invoice value covering additional from to

　　10. 付款条件

　　Terms of Payment

　　卖方收到50%定金后开始生产，发货前买方付清余款。

　　After the receipt of 50% of the total value payment, the seller shall begin the production and the buyer pay the balance of the total value before delivery.

　　11. 装运通知

　　Shipping Advice

　　一旦装运完毕，卖方应立即电告买方合同号、品名、已装载数量、发票总金额、毛重、运输工具名称及启运日期等。

　　The sellers shall immediately, upon the completion of the loading of the goods advise the buyers of the Contract No. names of commodity, loaded quantity, invoice value, gross weight, names of vessel and shipment date by TLX/FAX.

　　12. 交货原则

　　Delivery Policy

　　卖方在规定时间内所送货物必须符合订单要求，送错或送少，应及时更换或补货，否则，所带来的'损失由卖方全部承担。

　　The sellers within the prescribed time delivery of goods must comply with the order request, sent to the wrong or the less, should be replaced or replenishment, otherwise, the losses borne entirely by the sellers.

　　13. 推迟交货和罚款

　　Late Delivery and Penalty

　　如卖方没有按照合同规定准时交货，买方同意卖方付给罚款。加入卖方交货期超过7天，买方有权取消合同。取消合同的情况，卖方仍不能延误付给买方上述罚款。

　　Should the Sellers fail to make delivery on time as stipulated in the Contract, the Buyers shall agree to postpone the delivery on condition that the Sellers agree to pay a penalty. In case the Sellers fail to make delivery later than 7 days, the Buyers have the right to cancel the Contract and the Sellers, in spite of the cancellation, shall still pay the aforesaid penalty to the Buyers without delay.

　　14. 不可抗力

　　Force Majeure

　　如因人力不可抗拒的原因造成本合同全部或部分不能履约，卖方概不负责，但卖方应将上述发生的情况及时通知买方。

　　The sellers shall not hold any responsibility for partial or total non-performance of this contract due to Force Majeure. But the sellers shall advise the buyers on time of such occurrence.

　　15. 争议的处理

　　Disputes Settlement

　　所有与此合同有关的争议应通过友好协商解决，如果协商不能解决，根据有关仲裁法则进行仲裁。仲裁应在深圳进行且其结果对双方均有约束力，任何一方均不应向法院或其他政府部门申请以改变仲裁结果。仲裁费由负方负担。

　　All disputes in connection with this Contract or the execution thereof shall be settled friendly through negotiations. In case no settlement can be reached, the case shall be submitted for arbitration ，in accordance with its Rules of Arbitration. The arbitration shall take place in Shenzhen and the decision of the Arbitration Committee shall be final and binding upon both parties; neither party shall seek recourse to a law court nor other authorities to appeal for revision of the decision. Arbitration fee shall be borne by the losing party. Or the Arbitration may be settled in the third country mutually agreed upon by both parties.

　　16.文字

　　Versions

　　本合同中、英文两种文字具有同等法律效力，在文字解释上，若有异议，以中文解释为准。 This contract is made out in both Chinese and English of which version is equally effective. Conflicts between these two languages arising therefrom, if any, shall be subject to Chinese version.

　　17. 附加条款

　　Additional Clauses

　　本合同上述条款与本附加条款有抵触时，以本附加条款为准

　　Conflicts between contract clause hereabove and this additional clause, if any, it is subject to this additional clause.

　　18. 本合同一式两份，双方各执一份，自双方代表签字/盖章之日起生效。

　　This contract is made in copies, each party holds one, becomes effective since being signed/sealed by both parties.

　　买方（盖章）：

　　The Buyer (seal):

　　代表（签字）Representative (signature) ：

　　日期：

　　卖方（盖章）：

　　The Seller (seal):